michael rowlinson a practical guide to the nec3 engineering and construction contract isbn 9781444340167

Диапазон цен



Michael Rowlinson Practical Guide to the NEC3 Engineering and Construction Contract

Launched in 1993, the NEC Engineering and Construction Contract has become one of the UK's leading standard forms of contract for major construction and civil engineering projects. The third edition, popularly known as NEC3, is a process based contract embodying project and commercial management best practice, so its basic philosophy differs from the more adversarial approach of other standard construction contracts. Since the first edition of this book, the third edition of the contract has seen the introduction of a new secondary option for use in the UK and amendments to a number of clauses. In addition, in September 2011, changes were introduced to cater for the amendments to the Housing Grants, Construction and Regeneration Act 1996 contained in the Local Democracy, Economic Development and Construction Act 2009, which became effective for all new contracts entered into from 1 October 2011. These amendments have been incorporated into the text. A Practical Guide to the NEC3 Engineering and Construction Contract will be useful to everyone in the construction industry working on a project under this contract. It will be of interest to the complete construction supply chain, including employers, construction professions, contractors and sub-contractors, as well as consultants and lawyers advising any of these parties, either in the preparation of contract documentation or the day to day management or the resolution of problem situations which may arise.

7683.12 рублей

Купить сейчас

Michael Rowlinson A Practical Guide to the NEC4 Engineering and Construction Contract

Provides construction industry professionals with a practical and detailed guide to the NEC4 contract The NEC contract takes a collaborative, project management based approach to construction projects, which is very different to the other standard forms of construction contract. This new edition of the book covers all changes in the 4th Edition of the Engineering and Construction Contract, issued in June 2017, and will provide practical guidance to help users transitioning from NEC3 to NEC4. Inside A Practical Guide to the NEC4 Engineering and Construction Contract, readers will find chapters on the background of the NECECC; contract data and other documents; the‘spirit of mutual trust’; all of the individuals involved in the process (eg: project managers, clients, supervisors, subcontractors, etc.); communication issues, early warnings and other matters; quality management; titles; dealing with timing; payment processes; cost components; compensation procedures and assessments; dealing with terminations; dispute resolution; completing the contract and more. A practical guide to the application of the procedures contained in the newly issued NEC4 Engineering and Construction Contract Provides detailed guidance on the use of the agreement, which is claimed to offer increased flexibility, improved clarity and greater ease of use Written specifically for people actually using and administering the NEC contracts Features 3 appendixes covering tables of clause numbers, case law and statutes; employer’s, project manager’s, supervisor’s, contractor’s and adjudicator’s actions; and communication forms and their uses. First launched in 1993, the NEC has become one of the UK's leading standard forms of contract for major construction and civil engineering projects, making A Practical Guide to the NEC4 Engineering and Construction Contract a must-have resource for any contractor using the latest version of this contract.

11035.01 рублей

Купить сейчас

Michael Rowlinson A Practical Guide to the NEC3 Engineering and Construction Contract

Launched in 1991, the New Engineering Contract (NEC) has become one of the UK's leading standard forms of contract for major construction and civil engineering projects. Currently in the third edition, popularly known as NEC 3, it is a process based construction contract embodying project management best practice, and thus the basic philosophy behind the contract is different to the more adversarial principles and approach of other standard construction contracts. Written as a practical guide to the application of the procedures contained in NEC 3, this book will aid users in the transition from their use and understanding of the other standard construction contracts to the collaborative project management based approach of the ECC. Written for anyone working in the construction industry working on a project under the ECC, it will be of interest to the complete construction supply chain including employers, construction professions, contractors and sub-contractors. It will also be of interest to consultants and lawyers advising any of these parties, either in the preparation of contract documentation or the resolution of problem situations which may arise. A practical guide to the application of the procedures contained in the NEC Engineering and Construction Contracts Written specifically for people actually using and administering the NEC contracts – rather than lawyers Covers all the variations created by the Main and Secondary Options

9042.58 рублей

Купить сейчас

Michael Rowlinson Practical Guide to the NEC3 Professional Services Contract

Currently in its third edition, the NEC suite has become one of the UK’s leading families of standard forms of contract for major construction and civil engineering projects. Part of the NEC suite, the Professional Services Contract (PSC) was drafted with the same process-based approach and objectives, offering a standard contract for the appointment of consultants providing professional services in an engineering or construction project. Embodying best practice in terms of project management, the basic philosophy of the PSC differs from the principles and approach of other standard contracts used to appoint consultants. This book is a practical guide to the application of the PSC. Starting with a brief discussion of the background and philosophy behind the PSC, it identifies the roles and responsibilities of each of the named functions within the contract, explains the approaches required to achieve a successful working relationship between all parties, and examines all the procedures in the PSC. The book explains the links between the various sections of the contract to assist the reader with cross referencing, and covers all the variations created by the Main and Secondary Options. As a very practical guide it will aid users in the transition from their use and understanding of the other standard contracts to the collaborative project management-based approach of the PSC. Written for anyone working in the construction and related industries using the PSC to procure or provide consultancy services in relation to a construction project, it will be of interest to the complete construction supply chain, particularly architects, structural engineers, services (M&E) engineers, civil engineers, quantity surveyors and interior designers, together with Contractors and Sub-Contractors who have a design liability and employ consultants to assist them. It will also be of interest to consultants and lawyers advising any of these parties, either in the preparation of contract documentation or the resolution of problem situations which may arise.

9808.9 рублей

Купить сейчас

Steven Evans C. The Contractor's NEC3 ECC Handbook

Addresses the daily challenges faced by contractors who use the NEC3 ECC with clear, practical and useable advice on how to solve them Written in plain English for contractors and their staff, this book explains how the NEC3 contract works and provides answers to common questions. It presents complicated concepts in a simple, straightforward and understandable way, focusing mainly on day-to-day use. Steven Evans, an expert with thirty years of experience in construction, considers all the provisions of the contract and explains the procedures, obligations, and liabilities contained within it. NEC3 ECC is a process-based contract based on project management best practices. The basic philosophy behind it differs radically from the more adversarial approaches embodied by traditional contracts. While the NEC3 ECC may appear quite simple on the surface, it is often misunderstood and mismanaged by its day-to-day users. Despite the clear and urgent need for expert guides for those who use the NEC3 ECC, or who are considering adopting this increasingly popular contract, available books on the subject are highly technical and written for lawyers and professional consultants—until now. Written specifically for contractors using the NEC3 ECC contract, this book is aimed specifically at a level consistent with the knowledge and experiences of contractors and their staff. A practical guide to the procedures in the NEC3 Engineering and Construction Contracts Written specifically for those using and administering the contracts—not for lawyers or professional consultants Considers all the provisions of the contract and explains the procedures, obligations and liabilities Covers all NEC3 ECC versions and variations created by the Main and Secondary Options Provides clear, concise, practical, and straightforward explanations of the NEC3 ECC form used by commercial and operational staff of main contractors The Contractor's NEC3 EEC Handbook is a vital working resource for main contractors and their employees, including quantity surveyors, commercial managers, contracts managers, project managers, site managers, and estimators.

7123.25 рублей

Купить сейчас

Lukas Klee International Construction Contract Law

The updated second edition of the practical guide to international construction contract law The revised second edition of International Construction Contract Law is a comprehensive book that offers an understanding of the legal and managerial aspects of large international construction projects. This practical resource presents an introduction to the global construction industry, reviews the basics of construction projects and examines the common risks inherent in construction projects. The author – an expert in international construction contracts – puts the focus on FIDIC standard forms and describes their use within various legal systems. This important text contains also a comparison of other common standard forms such as NEC, AIA and VOB, and explains how they are used in a global context. The revised edition of International Construction Contract Law offers additional vignettes on current subjects written by international panel of numerous contributors. Designed to be an accessible resource, the book includes a basic dictionary of construction contract terminology, many sample letters for Claim Management and a wealth of examples and case studies that offer helpful aids for construction practitioners. The second edition of the text includes: • Updated material in terms of new FIDIC and NEC Forms published in 2017 • Many additional vignettes that clearly exemplify the concepts presented within the text • Information that is appropriate for a global market, rather than oriented to any particular legal system • The essential tools that were highlighted the first edition such as sample letters, dictionary and more • A practical approach to the principles of International Construction Contract Law and construction contract management. Does not get bogged down with detailed legal jargon Written for consulting engineers, lawyers, clients, developers, contractors and construction managers worldwide, the second edition of International Construction Contract Law offers an essential guide to the legal and managerial aspects of large international construction projects.

7343.9 рублей

Купить сейчас

Donald Towey Construction Quantity Surveying. A Practical Guide for the Contractor's QS

The revised and updated comprehensive resource for Quantity Surveyors working with a construction contractor The second edition of Construction Quantity Surveying offers a practical guide to quantity surveying from a main contractor's perspective. This indispensable resource covers measurement methodology (including samples using NRM2 as a guide), highlights the complex aspects of a contractor's business, reviews the commercial and contractual management of a construction project and provides detailed and practical information on running a project from commencement through to completion. Today’s Quantity Surveyor (QS) plays an essential role in the management of construction projects, although the exact nature of the role depends on who employs the QS. The QS engaged by the client and the contractor's QS have different parts to play in any construction project, with the contractor's QS role extending beyond traditional measurement activities, to encompass day-to-day tasks of commercial building activities including estimating, contract administration, and construction planning, as well as cost and project management. This updated and practical guide: Focuses on the application, knowledge and training required of a modern Quantity Surveyor Clearly shows how Quantity Surveying plays an essential central role within the overall management of construction projects Covers measurement methodology, the key elements of the contractor's business and the commercial and contractual management of a construction project The construction industry changes at fast pace meaning the quantity surveyor has a key role to play in the successful execution of construction projects by providing essential commercial input. Construction Quantity Surveying meets this demand as an up-to-date practical guide that includes the information needed for a Quantity Surveyor to perform at the highest level. It clearly demonstrates that quantity surveying is not limited to quantifying trade works and shows it as an important aspect of commercial and project management of construction projects.

4873.8 рублей

Купить сейчас

David Wright Using Commercial Contracts. A Practical Guide for Engineers and Project Managers

Using Commercial Contracts: a practical guide for engineers and project managers examines how the law of contract operates, and the way in which the legal system interprets what a contract actually means. By giving clear, readable and expert advice on key legal issues, this guide provides the manager and engineer with an easily understandable and practical approach to the laws of contract.

4873.8 рублей

Купить сейчас

Roger Gibson A Practical Guide to Disruption and Productivity Loss on Construction and Engineering Projects

Disruption of a construction project is of key concern to the contractor as any delay to the project will involve the contractor in financial loss, unless those losses can be recovered from the employer. It is, however, acknowledged that disruption claims in construction are difficult to prove, usually the result of poor or inaccurate project records, but the cost of lost productivity or reduced efficiency to the contractor under these circumstances is very real. Practical Guide to Disruption and Productivity Loss on Construction & Engineering Projects is clearly written to explain the key causes of disruption and productivity loss. Disruption claims rest on proof of causation, so it discusses the project records that are necessary to demonstrate the causes of disruption, lost productivity and reduced efficiency in detail. Quantification of a disruption claim in terms of delay to activities and the associated costs are also fully discussed. With many worked examples throughout the text, this will be an essential book for anyone either preparing or assessing a disruption and loss of productivity claims, including architects, contract administrators, project managers and quantity surveyors as well as contractors, contracts consultants and construction lawyers.

8060.16 рублей

Купить сейчас

Andy Hewitt Construction Claims and Responses. Effective Writing and Presentation

A practical, step-by-step guide for contracts managers, commercial managers, project managers, quantity surveyors, engineers and architects on the preparation of and responses to construction claims. Everyone involved in the preparation or review of construction claims should have this book to hand. The book examines the different types of claim common to construction contracts and presents a step-by-step guide to demonstrate the process of building up the submission of a claim and covers: Various types of claim. How the claim may be split into sections dealing with the details of the contract, the cause, the effect, entitlement and quantum. What this section is attempting to demonstrate or achieve and why. What should be included within the section and why. Worked examples of typical claims and responses with sample wording.

5122.08 рублей

Купить сейчас

Smith, Currie & Hancock LLP Smith, Currie and Hancock's Common Sense Construction Law. A Practical Guide for the Construction Professional

Cut through the legalese to truly understand construction law Smith, Currie & Hancock's Common Sense Construction Law is a guide for non-lawyers, presenting a practical introduction to the significant legal topics and questions affecting the construction industry. Now in its fifth edition, this useful guide has been updated to reflect the most current developments in the field, with new information on Public Private Partnerships, international construction projects, and more. Readers will find full guidance toward the new forms being produced by the AIA, AGC, and EJDC, including a full review, comparison to the old forms, areas of concern, and advice for transitioning to the new forms. The companion website features samples of these documents for ease of reference, and end of chapter summaries and checklists help readers make use of the concepts in practice. The updated instructor support material includes scenario exercises, sample curriculum, student problems, and notes highlighting the key points student responses should contain. Construction is one of the nation's single largest industries, but its fractured nature and vast economic performance leave it heavily dependent upon construction law for proper functioning. This book is a plain-English guide to how state and federal law affects the business, with practical advice on avoiding disputes and liability. Understand construction law without wading through legal theory Get information on an emerging method of funding large-scale projects Parse the complexities presented by international and overseas projects Migrate to the new AIA, AGC, and EJDC forms smoothly and confidently This book doesn't cover legal theory or serve as a lawyer's guide to case law and commentary – its strength is the clear, unaffected common-sense approach that caters to the construction professional's perspective. For a better understanding of construction law, Smith, Currie & Hancock's Common Sense Construction Law is an efficient reference.

10345.32 рублей

Купить сейчас

James Pickavance A Practical Guide to Construction Adjudication

In the United Kingdom, adjudication is available as a right for parties to a construction contract, following the enactment of the Housing Grants Construction and Regeneration Act 1996. In general, within a comparatively short period of time, parties in dispute will have a decision from an adjudicator, which, except in limited circumstances, the courts will enforce. Adjudication has become the number one method of dispute resolution in the construction industry. The short timescale means that a party needs to know what to do, when to do it and be able to check that the other party and the adjudicator are following the right steps. A Practical Guide to Construction Adjudication gives parties the necessary information to achieve this. It provides a straightforward overview of the process and procedure of adjudication by reference to legislation and case law, augmented with practical guidance including suggestions on what to do or not to do, drafting tips and checklists. Separate chapters for Scotland and Northern Ireland identify and explain the differences in procedure and judicial interpretation between those jurisdictions and England and Wales, and further detailed explanations of the adjudication regimes in Australia, Ireland, Malaysia, New Zealand and Singapore are included. Each of the chapters on jurisdictions outside England and Wales has been written by senior experts in those jurisdictions to ensure the content is accurate and insightful. There are a range of helpful appendices including a bank of model form adjudication documents and tabulated detailed comparisons of the Scheme for Construction Contracts, the other major adjudication rules, the major adjudicator nominating bodies and the UK and international regimes. Readers will particularly appreciate the most comprehensive index of adjudication cases available, sorted into 260 subject headings providing immediate access to all the reported cases on any adjudication topic.

6658.7 рублей

Купить сейчас

P. Keane John Delay Analysis in Construction Contracts

The most significant unanticipated costs on many construction projects are the financial impacts associated with delay and disruption to the works. Assessing these, and establishing a causal link from each delay event to its effect, contractual liability and the damages experienced as a direct result of each event, can be difficult and complex. This book is a practical guide to the process of delay analysis and includes an in-depth review of the primary methods of delay analysis, together with the assumptions that underlie the precise calculations required in any quantitative delay analysis. The techniques discussed can be used on projects of any size, under all forms of construction contract, both domestic and international. The authors discuss not only delay analysis techniques, but also their appropriateness under given circumstances, demonstrating how combined approaches may be applied where necessary. They also consider problematic issues including ‘who owns the float’, concurrent delay, early completion programmes, and disruption. The book has been brought fully up to date, including references to the latest publications from the CIOB, AACEI and SCL, as well as current case law. Broad in scope, the book discusses the different delay analysis approaches likely to be encountered on national and international projects, and features practical worked examples and case studies demonstrating the techniques commonly used by experienced practitioners. This is an invaluable resource to programmers and schedulers, delay analysts, contractors, architects, engineers and surveyors. It will also be of interest to clients’ professional advisors managing extension of time or delay claims, as well as construction lawyers who require a better understanding of the underlying assumptions on which many quantitative delay analyses are based. Reviews of First Edition «John Keane and Anthony Caletka are pukka analysts in that tricky area of delays, programming and extension of time. I highly recommend their book Delay Analysis in Construction Contracts. Buy the book.» (Building Magazine, February 2009) «The book′s stated purpose is to provide a practical guide for those interested in schedule delay analysis. It provides a good in–depth review of the most common delay analysis techniques.... An excellent book, full of practical tips for the reader and very timely in its publication. It is well worth the cost and a good read for anyone involved in schedule delay analysis.» (Cost Engineering, February 2009) It achieves in spades its stated aim of being a practical guide for contractors, contract administrators, programmers and delay analysts, as well as construction lawyers who require a better understanding of the underlying assumptions on which many quantitative delay analyses are based. (Construction Law Journal, 2009)

7170.91 рублей

Купить сейчас

Donald Towey Construction Quantity Surveying. A Practical Guide for the Contractor's QS

The modern quantity surveyor (QS) plays a central role in the management of construction projects, although the exact nature of the role depends on who employs the QS. The Professional Quantity Surveyor engaged by the client and the Contractor's Quantity Surveyor have different roles to play in any construction project, with the contractor's QS role extending beyond measurement to the day-to-day running of building projects, estimating, contract administration and construction planning, as well as commercial, cost and project management. This book aims to provide readers with a practical guide into quantity surveying from a main contractor's perspective. Readers will acquire an understanding of the skills and competencies required by the contractor’s quantity surveyor. Following a brief introduction, the book's early chapters cover measurement methodology and the contractor's business, with the rest of the chapters discussing commercial and contractual management of a construction project, including day-to-day running from commencement through to completion, in a highly practical way.

4904.45 рублей

Купить сейчас

Michael Robinson D. An Employer's and Engineer's Guide to the FIDIC Conditions of Contract

When all parties involved in the construction process fully understand their roles and are able to anticipate potential points of conflict, disputes and delays will be minimised. The Employer’s and Engineer’s Guide to the FIDIC Conditions of Contract sets out the essential administrative requirements of a FIDIC based contract by reference to the FIDIC 1999 Red Book. The obligations and duties of the Employer and the Engineer are identified and discussed. Potential pitfalls are highlighted and likely consequences pointed out. The importance of the Employer’s role in the preparation of tenders, which fully reflect his requirements and duties and obligations arising in the execution of the works, is emphasised. The key role of the Engineer in the effective administration of contracts after award is examined and commentary provided. Included in the guide are a number of appendices, including model letters which will be of value to less experienced staff (particularly those whose mother-tongue is not the English language). Engineers, quantity surveyors and project managers engaged in the contractual administration of international projects using FIDIC forms of contract will find the concise guidance in simple and jargon-free language provided here invaluable. This, together with the author’s earlier book, Contractor’s Guide to the FIDIC Conditions of Contract – which describes the duties, rights and responsibilities of the Contractor – represents the totality of supervision, design and execution of construction projects executed under the FIDIC Conditions of Contract. This book’s companion website offers invaluable resources to freely download, adapt and use: Model letters for use by the Employer Model letters for use by the Contractor Sample Interim Payment Certificate Model Form for Submissions to the Engineer Model Form of Engineer’s Order for Varied Works Model Form of Daywork/Daily Record Sheets

8019.61 рублей

Купить сейчас

Irene Lill The Engineer's Manual of Construction Site Planning

This handbook addresses problems facing the engineer when preparing to build, both during the contract bidding phase and after a contract has been concluded. It offers clear guidelines for planning the resources and machinery on site, as well as the safe positioning of roads, cranes, storage and temporary buildings. Site planning activities are presented here in logical sequence, offering an efficient and safe design of the construction site and of the temporary works. The book describes the process of engineering preparation of on-site construction works in all phases of the construction life-cycle, from the design phase – preparing the financial plan and procurement scheme for the owner before tendering the contract; the tendering phase; and after bid completion. A list of procedures is presented for planning the construction site in order to simplify the engineer’s work of site and temporary works planning. The Engineer’s Manual of Construction Site Planning is for all those involved in the planning of construction sites, construction managers, construction engineers and quantity surveyors, as well as for students in civil engineering and construction.

6823.75 рублей

Купить сейчас

Roger Woods Engineering Innovative Products. A Practical Experience

"The book provides vital insights into commercial development for engineering students in a highly practical and applied manner. Over the past 3 years, application of the book’s material has allowed the students to develop their commercial literacy and ambition in the University." —Steve Orr, Director, Northern Ireland Science Park CONNECT program which looks to accelerate the growth of knowledge-based companies in Northern Ireland Engineering Innovative Products: A Practical Experience is a pioneering book that will be of key use to senior undergraduate and graduate engineering students who are being encouraged to explore innovation and commercialization as part of their courses. The book will teach the essential skills of entrepreneurship and address the fundamental requirements needed to establish a successful technology company. As well as providing the crucial background and insights enabling students to identify a key market, it also offers a highly practical guide to undertaking genuine product validation and producing a feasibility study, as well as providing vital insights into the challenges and demands in forming a technology based company. Key features: Outlines how to develop and grow an engineering solution which has market potential and covers key business aspects of giving the perfect pitch, sales and marketing, protection of ideas and finance, to offer a complete and practical guide to commercializing ideas. Provides vital insight into the design and innovation processes within engineering and the challenges and pitfalls in translating good ideas into great products. Features contributions from leading experts in marketing, finance, company formation, sales and intellectual protection which provides details of the challenges faced by innovators when commercializing ideas. Includes Ccase studies from engineering students who give insights into how they have successfully developed their own ideas into companies.

4644.73 рублей

Купить сейчас

Nina Giglio M. Standards of Practice in Construction Specifying

Construction Specifications provide critical information necessary to convey the design intent of the Architect and the legally enforceable contract requirements. Many factors must be considered by the Architect in the development of written construction documents, including project delivery method, project ownership, sustainability, and code requirements. This companion guide to the 2013 AIA National Convention Presentation “Architect’s Guide to Construction Specifications” provides excerpts from important industry publications regarding the preparation of construction documents. Material was carefully selected from the following books: – CSI Construction Specifications Practice Guide – Architect’s Guide to the US National CAD Standard – CSI Construction Contract Administration Practice Guide – Architect’s Handbook of Professional Practice 14e Additional excerpts have been provided from CSI Formats to provide an overview of organizational standards for Specifications including: – MasterFormat – SectionFormat/PageFormat – PPDFormat Added material includes examples for comment document types, which can also be used as templates: Outline Specification; Short Form Specification; Certification and Seals Page; and Addendum This e-only book is an essential companion to the presentation or can stand alone as a necessary reference providing users ready access to key understanding of the methods of specifying; organizing structures for building information; and other components that should be considered in the preparation of a project manual.

1874.54 рублей

Купить сейчас
Обращаем ваше внимание — недорогая распродажа michael rowlinson a practical guide to the nec3 engineering and construction contract isbn 9781444340167 доступна с 08 утром до 20 часов вечером в 1 торговых центрах, между прочим доставка предлагается в Москве, Самаре, Саратове, Барнауле, Ставрополе и даже Мурманске, в том числе во многих второстепенных районах. У вас получится закказать в одном из рекомендованных интернет-магазинов — litres.ru, при средней стоимости 6600.45 рублей с НДС.

The most significant unanticipated costs on many construction projects are the financial impacts associated with delay and disruption to the works. Assessing these, and establishing a causal link from each delay event to its effect, contractual liability and the damages experienced as a direct result of each event, can be difficult and complex. This book is a practical guide to the process of delay analysis and includes an in-depth review of the primary methods of delay analysis, together with the assumptions that underlie the precise calculations required in any quantitative delay analysis. The techniques discussed can be used on projects of any size, under all forms of construction contract, both domestic and international. The authors discuss not only delay analysis techniques, but also their appropriateness under given circumstances, demonstrating how combined approaches may be applied where necessary. They also consider problematic issues including ‘who owns the float’, concurrent delay, early completion programmes, and disruption. The book has been brought fully up to date, including references to the latest publications from the CIOB, AACEI and SCL, as well as current case law. Broad in scope, the book discusses the different delay analysis approaches likely to be encountered on national and international projects, and features practical worked examples and case studies demonstrating the techniques commonly used by experienced practitioners. This is an invaluable resource to programmers and schedulers, delay analysts, contractors, architects, engineers and surveyors. It will also be of interest to clients’ professional advisors managing extension of time or delay claims, as well as construction lawyers who require a better understanding of the underlying assumptions on which many quantitative delay analyses are based. Reviews of First Edition «John Keane and Anthony Caletka are pukka analysts in that tricky area of delays, programming and extension of time. I highly recommend their book Delay Analysis in Construction Contracts. Buy the book.» (Building Magazine, February 2009) «The book′s stated purpose is to provide a practical guide for those interested in schedule delay analysis. It provides a good in–depth review of the most common delay analysis techniques.... An excellent book, full of practical tips for the reader and very timely in its publication. It is well worth the cost and a good read for anyone involved in schedule delay analysis.» (Cost Engineering, February 2009) It achieves in spades its stated aim of being a practical guide for contractors, contract administrators, programmers and delay analysts, as well as construction lawyers who require a better understanding of the underlying assumptions on which many quantitative delay analyses are based. (Construction Law Journal, 2009)

© 2019 Mededu51 . Охраняется законом РФ о СМИ | Разработано студией Flexi